|Tender Details : |
Object of the contract
Description: Contract notice: Engineering services
Authority Type: Regional or local authority
Contact Nature: Services
Procedure: Open procedure
Document: Contract notice
Award criteria: The most economic tender
CPV code: 71300000,71300000
CPV Description: Engineering services.
Extension of the Verna WWTP - Civil engineer.
Civil engineer services, phases 32 (partial), 41, 51, 52 and 53 according to RPH SIA 103 (2014) for civil engineering works (earthworks , shell, exterior landscaping); amount of the works giving right to the fees: CHF 8'700'000 (excluding taxes)
Main Site: STEP, Ecognens 1673 (FR).
Civil engineer servicesit, phases 32 (partial), 41, 51, 52 and 53 according to RPH SIA 103 (2014) for the works of civil engineering (earthworks, carcass work, external facilities); amount of the works giving right to the fees: CHF 8'700'000 (excluding taxes)
Partial offers are not allowed.
General Conditions: see tender documents.
Conditions governing the procedure: see documenTenders:
This call for tenders may be appealed to the Administrative and Public Law Court of the Cantonal Court, Av. Eugene-Rambert 15, 1014 Lausanne, filed within 10 days of publication; it must be signed and indicate the conclusions and reasons for the appeal. The impugned decision is attached to the appeal.
Closing delay for filingot offers / remarks: see tender document. The time of arrival for the offer is valid. The date of the postage stamp is not taken into consideration
Remarks (Deadline for writing questions) Questions are to be asked via the SIMAP forum
National reference publication: Simap of 10.11.2017, doc. 989543. Delay wants to ask some questionsin writing: 04.12.2017
Dossier available from 10.11.2017 to 11.01.2018
Conditions for obtaining the tender dossier: an additional file of project plans will be made available via SIMAP from 24.11.2017.
Internet address (URL): https://www.simap.ch
Directive: Classical Directive (2014/24/EU)