Procurement Summary
Country : Switzerland
Summary : Contract notice: Electrical machinery, apparatus, equipment and consumables; lighting
Deadline : 08 Mar 2019
Other Information
Notice Type : Tender
TOT Ref.No.: 30232431
Document Ref. No. : 047114-2019
Competition : ICB
Financier : Self Financed
Purchaser Ownership : -
Tender Value : Refer Document
Purchaser's Detail
Purchaser : SBB AG EINKAUF INFRASTRUKTUR ELEKTROANLAGEN UND ENERGIE
Office Name: SBB AG Einkauf Infrastruktur Elektroanlagen und Energie
Address: Hilfikerstrasse 3
Town: Berne
Postal Code: 3000
Contact Point: I-ESP-EI-TCN
Switzerland
Email :einkauf.energie@sbb.ch
URL :https://www.simap.ch
Tender Details
Object of the contract
Electrical machinery, apparatus, equipment and consumables; lighting
Description: Contract notice: Electrical machinery, apparatus, equipment and consumables; lighting
Authority Type: Utilities entity
Contact Nature: Supplies
Procedure: Open procedure
Document: Contract notice
Regulation: Agreement between the European Union and the Swiss Confederation
Award criteria: The most economic tender
CPV code: 31000000, 51000000, 31000000, 51000000
CPV Description: Electrical machinery, apparatus, equipment and consumables; lighting.
Installation services (except software).
Renewal of auxiliary installations UE Chatelard
SBB renews the electrical plant. This invitation to tender concerns the acquisition of the renewal of ancillary facilities.
Main Site: Chatelard electrical plant
SBB renews the electrical plant. This appThe tender covers the acquisition of the renewal of auxiliary facilities.
- 2 references of comparable projects completed during the last 7 years,
- ISO 9001 or equivalent certified quality management system,
- certified environmental management system ISO 14001 or comparable,
- general valid installation permit from the Federal Inspection of Neck Installationsstrong rage (ESTI) for Switzerland
Partial offers are not allowed.
Conditions for countries which have not acceded to the WTO Agreements: None.
General Conditions: According to the Request for Tender .
Negotiations: remain reserved.
Conditions governing the procedure: the contracting authority awards public contracts for services in Switzerland only to contractors who arerespect the provisions on the protection of workers, conditions of work and equal pay for men and women.
Other indications: offers and other elements of the contract must be submitted in the language of the contract indicated in Figure 2.4 of the terms of the tender. The various form templates exist in German, French and Italian, someEnglish, and may be requested to the Service mentioned in 1.2 of this publication. These documents are used solely for the purpose of translation.
Indication of remedies: in accordance with art. 30 LMP, this decision may be challenged, within 20 days of its publication at the Federal Administrative Court, PO Box, 9023 St. Gallen. The memory of rcopies, will indicate the conclusions, reasons and means of proof and will bear the signature of the Appellant or his representative; together with a copy of this publication and the documents invoked as evidence, where available.
National Reference Publication: SIMAP of 25.1.2019, doc. 1056823.
Delay would like to ask questions bywritten: 15.2.2019.
Internet address (URL): https://www.simap.ch
Documents
Tender Notice