Contract notice: Building construction work Tender, Switzerland - 40994477

Procurement Summary

Country : Switzerland

Summary : Contract notice: Building construction work

Deadline : 14 Apr 2020

Other Information

Notice Type : Tender

TOT Ref.No.: 40994477

Document Ref. No. : 095810-2020

Competition : ICB

Financier : Self Financed

Purchaser Ownership : -

Tender Value : Refer Document

Purchaser's Detail

Purchaser : ARMASUISSE IMMOBILIER
Office Name: Armasuisse immobilier
Address: Guisanplatz 1
Town: Berne
Postal Code: 3003
Contact Point: Marianne Zürcher



Switzerland
Email :marianne.zuercher@armasuisse.ch
URL :https://www.simap.ch

Tender Details

Object of the contract
Building construction work

Description: Contract notice: Building construction work

Authority Type: Ministry or any other national or federal authority
Contact Nature: Works
Procedure: Open procedure
Document: Contract notice
Regulation: GPA
Award criteria: The most economic tender
CPV code: 45210000, 45210000
CPV Description: Building construction work.

Drognens / FR, transformation and extension 1 stage, CFC 2315 photovoltaic installations

- photovoltaic installations,

Main Site: Drognens / FR (Rmont).

- photovoltaic installations,

- planning and construction of photovoltaic installations on 2 separate flat roofs of 1900 m (AO) and 500 m (BB). Services include execution planningtion, coordination, supply, delivery, installation, connection to the network, commissioning, administrative procedures, specific protocols and documentation, certificates, instruction for users of the 2 installations.

- extract from the commercial register, the prosecution office, certificate of payment of taxes, social charges and insurance, respeand collective labor agreements.

Construction cost code (CFC): 2315 electrical energy production equipment.

Partial offers are not accepted.

Conditions for countries which have not adhered to the agreements of the OMC: none.

General conditions: the specific provisions of Armasuisse real estate are contained in the tender documents.

Negotiations: demeurent reservedes.

Conditions governing the procedure: the contracting authority awards public contracts for services in Switzerland only to contractors who guarantee compliance with the provisions on worker protection, working conditions and equal pay for men and women women.

Other information: on the basis of the OMP, in article 13, paragraph 1, letter h, the adjudicator reserves the right, to award a new construction contract linked to a similar basic market in over-the-counter proceedings.

Indication of remedies: in accordance with art. 30 LMP, this publication may be attacked, within 20 days of its notification, before the Federal Administrative Court, PO Box, 9023 St. Gallen. The appeal brief, almostenter in 2 copies, indicate the conclusions, reasons and means of proof and bear the signature of the appellant or his representative; A copy of this publication and the documents invoked as evidence, when available, will be attached to it.the due date 14.4.2020 at Armasuisse real estate or to its attention at 1 Swiss post office (date of postage stamp 14.4.2020 (priority mail). Offers for which the deadline is not respected will not be taken into consideration The envelope must bear the mention: CFC 2315 Designation of the tender Do not open.

Remarks (delay wishes to ask questions in writing): questions must be formulated anonymously on the SIMAP forum (www.simap.ch) - of the submission concerned. Answers are given exclusively through this same platform until 30.3.2020. No warning will be sent. Questions received outside the deadline will not be dealt with.

National reference publication: SIMAP of 25.2.2020, doc. 1121235. DelaI wish to ask questions in writing: 20.3.2020.


Internet address (URL): https://www.simap.ch

Documents

 Tender Notice